Home / Terms And Conditions

U Measure It - Terms And Conditions:

print this page

THE PARTIES HERE TO COVENANT AND AGREE TO :

UMEASUREIT.COM,LLC., KNOWN AND DESIGNATED AS CONTRACTOR, TO PROVIDE STANDARD QUALITY, MATERIALS FREE FROM DEFECTS, INSTALLED IN A WORKMANLIKE MANNER. THE CONTRACTOR SHALL NOT BE RESPONSIBLE FOR DELAYS CAUSED BY WEATHER, SUBCONTRACTORS, MANUFACTURERS, ACTS OF GOD OR OTHER CIRCUMSTANCES BEYOND THE CONTRACTOR'S CONTROL. THE CONTRACTOR AGREES TO CARRY WORKMAN'S COMPENSATION AND PUBLIC LIABILITY INSURANCE AND TO PAY ALL STATE SALES TAXES, SOCIAL SECURITY AND UNEMPLOYMENT COMPENSATION TAXES ON MATERIALS AND LABOR FURNISHED UNDER THIS CONTRACT AS REQUIRED BY THE UNITED STATED GOVERNMENT AND THE STATE IN WHICH THIS WORK WAS PERFORMED. CUSTOMER TO PROVIDE APPROPRIATE BUILDING PERMITS AND TO PROVIDE SUFFICIENT INSURANCE TO COVER ALL MATERIALS ON THEIR PROPERTY DURING PROJECT. CUSTOMERS WILL MAKE ARRANGEMENTS TO ALLOW WORKMAN'S CONTINUOUS ACCESS TO SAID PROPERTY UNTIL ENTIRE JOB IS COMPLETE. ANY ALTERATIONS OR DEVIATIONS FROM THE SPECIFICATIONS INVOLVING EXTRA COSTS OF MATERIAL OR LABOR WILL ONLY BE EXECUTED UPON WRITTEN ORDER, AND WILL BECOME AN EXTRA CHARGE OVER THE SUM MENTIONED IN THIS CONTRACT. ALL AGREEMENTS MUST BE IN WRITING AND WILL BE BILLED SEPARATE FROM ORIGINAL ORDER. SEPARATE AGREEMENTS MADE WITH OUR WORKMEN ARE NOT RECOGNIZED. THIS INSTRUMENT SHALL BECOME BINDING ON THE ACCEPTANCE THEREOF IN WRITING BY SELLER OR UPON COMMENCING PERFORMANCE OF THE WORK. IT BEING UNDERSTOOD THAT THIS INSTRUMENT, UPON SUCH ACCEPTANCE CONTAINS ALL AND THE ONLY AGREEMENT BETWEEN SELLER AND BUYER AND THAT NO REPRESENTATIVE OF SELLER HAS MADE STATEMENTS, REPRESENTATIONS OR AGREEMENTS , VERBAL OR WRITTEN, MODIFYING OR ADDING TO THE TERMS AND CONDITIONS HEREIN SET FORTH. SEPARATE AGREEMENTS MADE BY OUR WORKMEN ARE NOT RECOGNIZED. FREE IN-HOME ESTIMATES MAY NOT REFLECT PRICES FOR ONLINE SALES. IN THE EVENT OF AN ATTEMPT TO CANCEL THIS CONTRACT ANY AND ALL DOWN PAYMENTS OR 25% OF TOTAL CONTRACT TO INCLUDE APPLICABLE SALES TAX, WHICHEVER IS GREATER, AS LIQUIDATION COSTS FOR BREACH OF CONTRACT IF CONTRACT CONSISTS OF CUSTOM MADE PRODUCTS SUCH AS WINDOWS, THE FULL BALANCE OF CONTRACT SHALL BE DUE AND PAYABLE. BUYER AGREES TO THE TERMS OF THIS CONTRACT AND UPON AGREEMENT THIS CONTRACT REPRESENTS AND WARRANT THAT HE/SHE IS THE OWNER OF THE PROPERTY TO BE IMPROVED. IN THE EVENT TERMS ARE NOT MET, CUSTOMER ALSO AGREES TO PAY 1-1/2% PER MONTH CARRYING CHARGE OR SUCH CHARGES AS ALLOWED BY LAW.CUSTOMER ALSO AGREES TO PAY ANT REASONABLE COLLECTION COSTS OR ATTORNEY FEES IF APPLICABLE. IN THE EVENT THE OWNER SHALL SELL OR DISPOSE OF THE LAND AND PREMISES OR COMMIT AN ACT OF BANKRUPTCY OR ALLOW A JUDGMENT OR LIEN TO BE REGISTERED AGAINST THE LAND OR PREMISES, THE WHOLE UNPAID BALANCE IS IMMEDIATELY DUE AND PAYABLE. YOU ARE HEREBY NOTIFIED THAT THE SELLER INTENDS TO FILE A MATERIAL LIEN FOR THE AFOREMENTIONED LABOR AND MATERIALS UNLESS THE TOTAL PRICE IS PAID AS AGREED. ALL SURPLUS MATERIAL IS THE PROPERTY OF THE CONTRACTOR. ANY CONTROVERSY OF CLAIM ARISING OUT OF OR RELATING TO THIS CONTRACT OR ANY BREACH THEREOF SHALL BE SETTLED IN ACCORDANCE WITH THE ARBITRATION RULES OF THE CONSUMER BUSINESS ARBITRATION TRIBUNAL OR THE BETTER BUSINESS BUREAU.

ALL CHECKS OR MONEY ORDERS ISSUED ARE TO BE MADE TO THE CONTRACTOR.

1. WHEN THE WORK IS FINISHED THE CONTRACTOR AGREES TO CLEAN UP THE CONSTRUCTION SITE AND REMOVE OLD WINDOWS, DOORS, AND RELATED MATERIALS.
2. THE WORK TO BE PERFORMED DOES NOT INCLUDE DRY ROT OR INSECT DAMAGE REPAIR, UNLESS SPECIFIED IN WRITING ON THE WORK ORDER. IF DRY ROT IS DISCOVERED DURING INSTALLATION AND MUST BE REPAIRED IN ORDER TO FINISH THE WORK AS ORDERED, THE CUSTOMER AGREES TO ASSUME ANY REASONABLE ADDITIONAL COSTS OR MAKE SEPARATE ARRANGEMENTS FOR ROT REPAIR AT THEIR OPTION.
3. THE WORK TO BE PERFORMED DOES NOT INCLUDE PAINTING OR REFINISHING WOOD THAT MIGHT BE USED TO TRIM THE WINDOWS. WINDOWS AND DOORS WILL BE CAULKED OUTSIDE AND INSIDE AS NEEDED.
4. THE PARTIES AGREE THAT THE CONTRACTOR DOES NOT GUARANTEE "NO WEEPING" AS THIS IS A CONDITION BEYOND THE CONTRACTORS CONTROL.
5. THE CONTRACTOR IS NOT RESPONSIBLE FOR DAMAGE TO EXTERIOR SIDING,SPLITTING, CRACKING,DENTING, ETC. DURING INSTALLATION; OR DAMAGE TO EXISTING TILE LINERS AROUND WINDOWS.
6. THE CONTRACTOR WILL NOT BE RESPONSIBLE FOR ALARM REINSTALLATION.
7. THIS CONTRACT IS SUBJECT TO ACCEPTANCE OR REJECTION BY THE MANAGEMENT OF UMEASUREIT.COM. TITLE TO THE MERCHANDISE DOES NOT PASS TO THE BUYER UNTIL THE ENTIRE PURCHASE PRICE HAS BEEN PAID.
8. THE CUSTOMER WILL TAKE FULL RESPONSIBILITY FOR MEETING ALL BUILDING CODES.
9. UMEASUREIT ASSUMES NO RESPONSIBILITY FOR VARYING ENERGY CODES. UMESUREIT OFFERS A FULL LINE OF PRODUCTS TO MEET CODES IN ALL AREAS. THE CUSTOMER WILL ACCEPT FULL RESPONSIBILITY FOR MAKING SURE ALL CODES IN THE AREA OF USE WILL BE MET.
10. ALL ORDERS MADE ONLINE WILL RECEIVE AN AUTOMATED EMAIL CONFIRMATION.
11. ALL ORDERS FOR INSTALLED WINDOWS WILL BE RE-MEASURED AT THE INSTALLATION SITE BY REPRESENTATIVES OF UMEASUREIT.
12. GROSS MISREPRESENTATION OF SIZES OF WINDOWS BY PROPERTY OWNER, CAN CAUSE UMEASUREIT TO CANCEL ORDER, AND DEMAND A MEASURE AND HANDLING FEE NOT TO EXCEED $200.OO
    

NOTICE TO CUSTOMER:
PURSUANT TO RCCW18.27, UMEASUREIT.COM,LLC IS REQUIRED BY THE STATE OF WASHINGTON TO NOTIFY YOU THAT IT IS REGISTERED WITH THE STATE OF WASHINGTON, REGISTRATION NUMBER UMEASL*934CB, AS A GENERAL CONTRACTOR AND HAS POSTED WITH THE STATE A BOND OR CASH DEPOSIT OF $12,000.00 FOR THE OF SATISFYING CLAIMS AGAINST THE CONTRACTOR FOR NEGLIGENT OR IMPROPER WORK OR BREACH ON YOUR CONTRACT IN THE CONDUCT OF THE CONTRACTORS BUSINESS. THIS BOND OR CASH DEPOSIT MAY NOT BE SUFFICIENT TO COVER A CLAIM, WHICH MIGHT ARISE FROM THE WORK DONE UNDER YOUR CONTRACT. IF ANY SUPPLIER OF MATERIAL USED IN YOUR CONSTRUCTION PROJECT OR ANY EMPLOYEE OF THE CONTRACTOR OR SUBCONTRACTOR IS NOT PAID BY THE CONTRACTOR OR SUBCONTRACTOR ON YOUR JOB, YOUR PROPERTY MAY BE LIENED TO FORCE PAYMENT. IF YOU WISH ADDITIONAL PROTECTION, YOU MAY REQUEST THE CONTRACTOR TO PROVIDE YOU WITH THE ORIGINAL "LIEN RELEASE" DOCUMENTS FROM EACH SUPPLIER OR SUBCONTRACTOR ON YOUR PROJECT. THE CONTRACTOR IS REQUIRED TO PROVIDE YOU WITH FURTHER INFORMATION ABOUT LIEN RELEASE DOCUMENTS IF YOU REQUEST IT. GENERAL INFORMATION IS ALSO AVAILABLE FROM THE DEPARTMENT OF LABOR AND INDUSTRIES.